Last updated: April 1, 2026
These Terms of Service ("Terms") constitute a legally binding agreement between you ("Client", "you", or "your") and Cameron Mobile Technologies ("CMT", "we", "us", or "our"), a company registered in the Netherlands with its principal office in Amsterdam.
By accessing our website at cameronmobiletech.com, submitting an inquiry, or engaging our services, you confirm that you have read, understood, and agree to be bound by these Terms. If you do not agree, please do not use our website or services.
These Terms are governed by and construed in accordance with the laws of the Netherlands and, where applicable, mandatory provisions of European Union law, including the General Data Protection Regulation (GDPR).
"Application" or "App" means any mobile application, web application, or software product developed by Cameron Mobile Technologies for or on behalf of the Client.
"Growth Path" means the service model whereby Cameron Mobile Technologies develops and hosts the Application at no upfront development cost, the Application is published under Cameron Mobile Technologies' app store accounts, and the Client pays a recurring hosting fee and a per-transaction service fee in EUR.
"Ownership Path" means the rent-to-own service model whereby the Client pays a higher monthly fee in EUR over an agreed term (12, 18, or 24 months), at the conclusion of which full ownership of the source code and intellectual property transfers to the Client.
"Full Purchase" means the traditional development model whereby the Client pays a fixed project fee in EUR and receives full ownership of the Application and source code upon completion and final payment.
"Service Fee" means the per-transaction percentage or fixed fee charged by Cameron Mobile Technologies on sales or transactions processed through the Application under the Growth Path model.
"Hosting Fee" means the recurring monthly fee in EUR payable for the hosting, server infrastructure, and operational maintenance of the Application.
"Service Agreement" means the specific written agreement between Cameron Mobile Technologies and the Client detailing the scope, deliverables, pricing, timelines, and terms applicable to a particular project.
Cameron Mobile Technologies provides mobile and cross-platform application development services using Kotlin Multiplatform and related technologies. Our services are offered under three primary engagement models:
Under the Growth Path, Cameron Mobile Technologies develops the Application at no upfront cost to the Client(Qualified Clients Only). The Application is published on the Apple App Store and/or Google Play Store under Cameron Mobile Technologies' developer accounts. Cameron Mobile Technologies retains ownership of the Application, its source code, and all associated intellectual property. The Client pays a monthly hosting fee in EUR for server infrastructure and maintenance. Cameron Mobile Technologies charges a service fee on each transaction processed through the Application. The specific hosting fee and service fee percentages will be set out in the Service Agreement.
Under the Ownership Path, the Client pays a higher monthly fee in EUR over an agreed period (12, 18, or 24 months). The Application is published under our app store accounts. Upon completion of all payments under the agreed term, full ownership of the source code and intellectual property transfers to the client and the app will be transfered to the client's Apple Developer and Google Play developer accounts. Cameron Mobile Technologies will provide complete source code, documentation, and a handover briefing. Optional ongoing maintenance and support is available under a separate agreement.
Under the Full Purchase model, the Client pays a fixed project fee in EUR as agreed in the Service Agreement. The Client must register and maintain their own app store developer accounts. Upon full and final payment, the Client receives complete ownership of the Application, source code, and associated intellectual property. Cameron Mobile Technologies retains the right to use anonymised, non-proprietary code patterns and frameworks developed during the project for future work.
All intellectual property in the Application, including but not limited to the source code, design, architecture, and any custom libraries or modules, remains the sole property of Cameron Mobile Technologies for the duration of the Growth Path engagement. The Client is granted a non-exclusive, non-transferable licence to use the Application for the purposes set out in the Service Agreement, for as long as the Client remains in good standing with all payment obligations.
During the payment term, intellectual property remains with Cameron Mobile Technologies. Upon successful completion of all payments, intellectual property transfers to the Client in full. If the Client defaults on payments, Cameron Mobile Technologies retains all intellectual property rights and may, at its discretion, suspend or terminate access to the Application.
Upon receipt of full and final payment, all intellectual property in the bespoke Application transfers to the Client. Cameron Mobile Technologies retains the right to use general, non-proprietary techniques, tools, and methodologies developed or utilised during the project.
The Client retains all rights to content, data, branding, trademarks, and materials provided to Cameron Mobile Technologies for use in the Application. The Client grants Cameron Mobile Technologies a limited licence to use such materials solely for the purpose of providing the agreed services.
5.1 All fees are quoted and payable in Euro (EUR). Invoices are issued in accordance with Dutch VAT (BTW) regulations.
5.2 Hosting fees are payable monthly in advance. Invoices are issued on the first business day of each month and are due within 14 (fourteen) days of issue.
5.3 Transaction-based service fees under the Growth Path are calculated monthly and invoiced in arrears, based on transaction data recorded by the Application's payment processing system.
5.4 Ownership Path monthly payments are due on the same day each month as specified in the Service Agreement. Failure to make two consecutive payments constitutes a material breach.
5.5 Full Purchase payments are structured as per the Service Agreement, typically with a deposit, milestone payments, and a final balance upon delivery.
5.6 Late payments may attract statutory commercial interest as provided under Dutch law (Wet betalingstermijnen), plus reasonable collection costs. Cameron Mobile Technologies reserves the right to suspend services in the event of non-payment exceeding 14 days after a written reminder.
5.7 All fees are exclusive of Value Added Tax (BTW), which will be charged at the applicable Dutch rate (currently 21%). Reverse charge mechanism may apply for B2B clients within the EU holding a valid VAT identification number.
6.1 Growth Path: Cameron Mobile Technologies publishes and maintains the Application under its own Apple Developer and Google Play developer accounts. The Application listing, metadata, and updates are managed by Cameron Mobile Technologies. The Client may request reasonable changes to the listing, subject to app store guidelines.
6.2 Ownership Path and Full Purchase: The Client is responsible for creating, maintaining, and paying for their own Apple Developer account (currently USD $99/year) and Google Play Developer account (currently USD $25 one-time fee). Cameron Mobile Technologies will publish the Application to the Client's accounts and may require temporary access credentials to do so.
The Client agrees to provide all required content, branding materials, and specifications in a timely manner. The Client shall ensure that all content and materials provided do not infringe upon the intellectual property rights of any third party. The Client is responsible for the accuracy of all information provided. Delays caused by the Client's failure to provide necessary materials may result in revised timelines and, where applicable, additional costs.
8.1 Cameron Mobile Technologies will perform all services with reasonable skill and care, in accordance with generally accepted industry standards.
8.2 For hosted applications (Growth Path), Cameron Mobile Technologies targets an uptime of 99.9%, excluding scheduled maintenance, force majeure events, and third-party service outages beyond our control.
8.3 Cameron Mobile Technologies does not warrant that the Application will be entirely free of bugs or errors. We will use reasonable efforts to resolve reported issues in a timely manner.
8.4 To the fullest extent permitted by Dutch law, all other warranties, whether express or implied, are excluded. Nothing in these Terms is intended to limit any mandatory consumer rights under EU or Dutch law.
9.1 To the maximum extent permitted by Dutch law, Cameron Mobile Technologies' total liability arising out of or in connection with the services shall not exceed the total fees paid by the Client to Cameron Mobile Technologies in the 12 months preceding the event giving rise to the claim.
9.2 Cameron Mobile Technologies shall not be liable for any indirect, incidental, special, consequential, or punitive damages, including but not limited to loss of profits, data, business opportunity, or goodwill.
9.3 Cameron Mobile Technologies shall not be liable for any losses resulting from third-party services, including app store policy changes, payment processor failures, or hosting provider outages.
Either party may terminate the Growth Path engagement by providing 30 days' written notice. Upon termination, Cameron Mobile Technologies will remove the Application from the app stores within a reasonable time. The Client's data (excluding source code and intellectual property, which remain with Cameron Mobile Technologies) will be provided to the Client in a standard format. The Client may, at the time of termination, negotiate a buyout of the source code at fair market value.
If the Client terminates prior to completing all payments, no intellectual property transfers. Payments already made are non-refundable unless otherwise agreed. If Cameron Mobile Technologies terminates for reasons other than Client breach, a pro-rata refund may apply at Cameron Mobile Technologies' discretion.
Termination is governed by the Service Agreement. Deposits and milestone payments for work already completed are non-refundable.
Either party may terminate immediately upon written notice if the other party commits a material breach and fails to remedy such breach within 14 days of receiving written notice (ingebrekestelling) of the breach.
Both parties agree to comply with the General Data Protection Regulation (GDPR) and the Dutch GDPR Implementation Act (UAVG). Where Cameron Mobile Technologies processes personal data on behalf of the Client, it does so as a data processor and a Data Processing Agreement (Verwerkersovereenkomst) shall be entered into. Our full privacy practices are detailed in our Privacy Policy.
Neither party shall be liable for any delay or failure to perform its obligations where such delay or failure results from circumstances beyond the party's reasonable control (overmacht), including but not limited to natural disasters, epidemics, government actions, power failures, internet outages, acts of war or terrorism, and strikes.
13.1 The parties shall first attempt to resolve any dispute through good-faith negotiation.
13.2 If the dispute is not resolved within 30 days, either party may refer the dispute to mediation in Amsterdam, the Netherlands.
13.3 If mediation is unsuccessful, the dispute shall be submitted to the exclusive jurisdiction of the courts of Amsterdam (Rechtbank Amsterdam).
These Terms are governed by and construed in accordance with the laws of the Netherlands. The United Nations Convention on Contracts for the International Sale of Goods (CISG) is expressly excluded. The parties submit to the exclusive jurisdiction of the courts of Amsterdam.
Severability: If any provision of these Terms is found to be invalid or unenforceable, the remaining provisions shall continue in full force and effect.
Entire Agreement: These Terms, together with the applicable Service Agreement and Privacy Policy, constitute the entire agreement between the parties.
Amendments: Cameron Mobile Technologies reserves the right to amend these Terms. Material changes will be communicated to active clients.
Cameron Mobile Technologies
Amsterdam, North Holland, the Netherlands
KVK: 91316804